- Office Hours: Monday - Saturday 9 AM - 6 PM
1. Introduction & Effective Date
Welcome to Millennial Landscaping Inc. These Terms and Conditions govern your participation in our Fire Place Offer. By claiming this offer, you agree to be bound by these terms. This agreement is effective as of the date you accept the offer or sign any related contract.
Effective Date: January 1, 2025
2. Eligibility
- To be eligible for the Fire Place Offer, you must:
- Be a homeowner or authorized representative of a property located within our service area in San Diego County, California
- Be at least 18 years of age
- Have a suitable outdoor space that meets our installation requirements
- Obtain any necessary permits or homeowner association approvals prior to installation
- Not have any outstanding balances or disputes with Millennial Landscaping Inc.
3. Offer Details
What's Included:
- Custom fire place design consultation
- Professional installation by certified technicians
- Standard materials as specified in your quote
- Basic site preparation
- One-year warranty on installation workmanship
What's Excluded:
- Premium materials or custom upgrades (available at additional cost)
- Extensive site work, grading, or excavation beyond standard preparation
- Gas line installation or modifications (if applicable)
- Permit fees and inspection costs
- Removal of existing structures or hardscaping
Time Limits:
This offer must be claimed within 30 days of receipt. Installation must be scheduled within 90 days of offer acceptance, subject to availability and weather conditions.
4. Booking & Payment Terms
Deposit: A non-refundable deposit of 50% of the total project cost is required to secure your booking and schedule installation. This deposit is due upon signing the contract.
Final Payment: The remaining 50% balance is due upon completion of the installation and your approval of the finished work. We accept cash, check, credit card, and electronic payments.
Price Changes: Prices are locked in upon contract signing. However, additional charges may apply if you request changes to the scope of work, or if unexpected site conditions require additional materials or labor.
5. Installation & Scheduling
Scheduling: We will work with you to schedule a mutually convenient installation date. Installation timelines may vary based on project complexity, weather, and material availability.
Weather Delays: Outdoor construction is subject to weather conditions. In the event of rain, extreme heat, or other adverse weather, installation may be delayed for safety and quality reasons. We will communicate any delays promptly and reschedule at the earliest opportunity.
Site Conditions: You are responsible for ensuring clear access to the installation area and adequate utility markings. If we encounter unforeseen site conditions (e.g., underground utilities, poor soil, irrigation systems), we will inform you immediately. Additional work required due to these conditions may result in extra charges.
Permits: You are responsible for obtaining any required permits and homeowner association approvals. Millennial Landscaping can assist with this process for an additional fee if requested.
6. Warranty & Maintenance
Workmanship Warranty: We provide a one-year warranty on installation workmanship. This covers defects in our work but does not cover damage caused by misuse, neglect, natural disasters, or normal wear and tear.
Materials: Materials are covered by their respective manufacturers’ warranties. We will assist you with warranty claims as needed.
Maintenance: Proper maintenance is your responsibility and is essential to preserving the beauty and functionality of your fire place. We recommend regular cleaning, seasonal inspections, and adherence to all manufacturer guidelines. Failure to maintain the installation may void the warranty.
7. Cancellation & Refund Policy
By Customer: If you cancel after signing the contract but before work begins, your deposit is non-refundable. If you cancel after work has commenced, you will be charged for all work completed, materials purchased, and labor expended, with any overpayment refunded.
By Company: We reserve the right to cancel or reschedule your project if unforeseen circumstances arise (e.g., extreme weather, material shortages, safety concerns). In such cases, we will provide a full refund of any payments made if we cannot complete the work within a reasonable timeframe.
8. Limitation of Liability & Indemnity
To the fullest extent permitted by law, Millennial Landscaping Inc.’s liability for any claims arising from this offer is limited to the total amount you paid for the fire place installation. We are not liable for indirect, incidental, consequential, or punitive damages.
You agree to indemnify and hold harmless Millennial Landscaping Inc. and its employees from any claims, damages, or expenses arising from your failure to obtain proper permits, misrepresentation of site conditions, or misuse of the installed fire place.
9. Changes to Terms
Millennial Landscaping Inc. reserves the right to modify, update, or discontinue this offer and these Terms and Conditions at any time without prior notice. Any changes will be effective immediately upon posting to our website or notification to you. Your continued participation in the offer after changes are made constitutes acceptance of the revised terms.
10. Governing Law
These Terms and Conditions are governed by and construed in accordance with the laws of the State of California, without regard to its conflict of law principles. Any disputes arising under or related to these terms shall be resolved in the courts of San Diego County, California.
Millennial Landscaping Inc.
- 858-288-1412
- millenniallandscapinginc@gmail.com
- Millennial Landscaping Inc San Diego, CA,
- San Diego
At Millennial Landscaping, our team is the cornerstone of our reputation. Each member brings a unique blend of creativity, precision, and passion to the table.
- Support
- Privacy Policy
- Terms and Conditions
- Contact
- 858-288-1412
-
millenniallandscapinginc@
gmail.com - Millennial Landscaping Inc San Diego, CA,